Contractor Not Entitled to Additional Recovery for Government-Caused Delay Addressed by Contract Modification; COFC No. 10-707C, Oasis International Waters Inc. v. United States

Appeal of a contracting officer’s final decision denying a claim based on differing site conditions and delay is denied, where a previous ruling established that the government was not liable for differing site conditions and where the delay damages were precluded by accord and satisfaction stemming from a bilateral contract modification.