Delay in Assessing Liquidated Damages Did Not Waive Contract Deadline; ASBCA Nos. 61518, Appeals of Watts Constructors LLC

The government’s motion to dismiss an appeal of the termination for default of the appellant’s construction contract is granted in part, where the government never waived the completion date, even though it did not begin assessing liquidated damages until several months after the initial project completion date.