Repeatedly Missed Completion Dates Enough Cause to Support Termination for Default; ASBCA No. 60647, Appeal of ECC CENTCOM Constructors LLC

Appeal of the agency’s termination of a contract for default is denied, where the board lacked jurisdiction to consider the contractor’s allegations of excusable delay because they had not been presented to the contracting officer as either a claim or request for equitable adjustment.