Appellant Failed to Provide Realistic Completion Schedule to Agency Prior to Termination for Default; ASBCA No. 60410, Appeal of Coastal Environmental Group Inc.

Appeal of the termination for default of a construction contract is denied, where the appellant failed to show that it provided the agency with a realistic plan for completing the work by the agreed-upon deadline, and where an earlier modification precluded the appellant from arguing that a pre-modification government-caused delay contributed to the work delays.