Compensation for Changed Work Not Enough to Fully Compensate for Unchanged Work According to CBCA

In Industrial Maintenance Services, CBCA 5618, the Civilian Board of Contract Appeals (CBCA) found a contractor was entitled to additional payment where the Agency paid certain direct costs associated with a change in the critical path of performance, but failed to include the costs of impacted, unchanged work in the modification.