Defaulting Contractor Fails to Prove Key Personnel Resignations Resulted in Excusable Delay; CBCA 4079, Asheville Jet Charter & Management, Inc. v. Department of the Interior

Appeal of the Civilian Board of Contract Appeals’ decision affirming the government’s termination for default is denied, where the resignations of key personnel did not constitute a strike beyond the appellant’s control and therefore the contractor did not have a valid defense under the excusable delay clause.